Appellant is a -drainage district, organized for the purpose of 'constructing a drainage system in a large area in Lonoke County. The plans contemplated 69.8 miles of -ditches, including Bayou Meto for a distance- of twenty-five miles, the main ditch, 22 miles in length, and eleven lateral ditches, and a cut-off ditch, in addition to cleaning and dredging Bayou Meto for a distance of 25 miles to make it part of the system. Appellee was the successful bidder for the work, and entered into a written contract with appellant. The work was begun in the year 1920, and most of the work was completed in the year 1922, and there was a final *1159completion, according to th^. finding-, by the chancery court, on May 1, 1923. This is an action instituted by appellee to recover the balance alleged to be due for work clone under the contract. Appellant answered denying the amount of earned compensation claimed by appellee, and also filed a counterclaim for damages on account of alleged defective work and for delay in completing the improvement.
Tiie contract called for payment for the work on estimates of the engineer, with the retention of twenty per cent, of each item, to 'be held back until completion of the contract. It is agreed by both parties that the aggregate retained percentage was $71,763.17, the controversy arising over additional items for which appellee made claim and over items of damage claimed by appellant in reduction of the amount due from retained percentage. There was a reference made to a master, who was to take testimony and state the account, which was done, and the court, on hearing the exceptions to the master’s report, rendered a decree in favor of appellee for the sum of $96,102.17, and dismissed appellant’s cross complaint for want of equity. There is a small item of $69.48 to be added to the retained percentage, about which there is no controversy except as to allowance of interest thereon. The interest item on that amount is very small, but we see no reason why appellee is not entitled to it.
The first item of any importance claimed by the appellee, in addition to the amount of retained percentage, and which was allowed by the chancery court, is the sum of $9,097.59 for work done on what is termed force account. Section 25 of the specifications reads as follows:
"Force Account. All -work not contemplated or set out in. these plans or specifications, which will be later found necessary to be done, will be done !by the contractor at the actual cost to him, as determined by the engineer, plus 15 per cent. Under this head would come such items as removing and replacing fences, bridges, re*1160moving houses, and all other work that cannot he foreseen at this time. Extra work will be paid for only on the written order from the engineer, and should not he undertaken without the engineer’s written order to do so.”
The claim is based on work done in clearing the right of way. The controversy relates to certain sections of the work along Bayou Meto, which is-a deep and wide stream of water with high hanks in some places and low banks in other places. The specifications in regard to clearing reads, originally, as follows:
“Right-of-Way Clearing. The right-of-way should be a minimum of eighty feet, and in general should be equal to the bottom width of the ditch, plus seventy feet. Widths above that at the discretion of the board and the engineer. Right-of-way for team ditches should not be less than enough to leave a clear ten-foot berm on each side and room for the waste banks.
“All trees and shrubs are to be cut off the entire right-of-way and burned or otherwise removed, to the end that the right-of-way may have a clean, neat appearance. Clearing will be paid for per acre per price bid.”
However, before the. contract was let to appellee, the last paragraph of § 24 was changed to read as follows:
“That all trees and shrubs are to be cut off the entire right-of-way and removed back or under the spoil-banks, to the end that the right-of-way have a clean, neat appearance. ’ ’
Other parts of the contract provided that the Bayou Meto excavation should be a width of fifty feet at the bottom, with sloping banks, and the evidence shows that the excavation work was intended to be done, and was done, with a large dredge boat fifty-four feet in width with a boom of sufficient length to deposit the waste seventy-five feet on each side from the center of the stream or ditch. The evidence also shows that it was the intention of appellant to cut the trees, and then remove the stumps and trunks and debris with the dipper of the dredge. All of the parties connected with the work, *1161including- the commissioners, doubtless ha.d in mind that the clearing would be done in that way at the time the contract was made, but there is no specification in the contract with reference to that part of the work except those provisions quoted above. That method was pursued in doing- the clearing- from the beginning- of the work on Bayou Meto at station 3 up to station 429 when it was found that on account of the low banks and the depth of the stream there was not enough waste material to cover the logs, stumps and other debris so as to prevent it floating- back into the stream in times of high water and the same could not be handled and deposited by the dredge boat outside of the limits of the right-of-way; hence it was found necessary to clear the right-of-way by use of teams so that the debris could be hauled outside the limits of the right-of-way. Appellee claims that this constituted a change in the contract for which he is entitled to extra pay on force account, as provided in § 25 of the specifications. The chancery court took this view of the matter and allowed appellee the item of $9,097.59, which included the cost of clearing and the fifteen per cent, additional provided by the contract for payment on force account. Our conclusion is that the allowance was improper, and that the item did not fall within the clause providing for payment for extra work. Section 25 -was not intended to cover extra cost of different methods of doing the work unless it constituted a change in the plans and specifications. The intention of the parties, as gathered from a fair interpretation of the language used, is that it was to provide compensation for work which was not specified in the contract. There could be no claim on account of change in the method of doing the clearing, for there was no method specified. All that the contract provided on that subject was that the “ trees and shrubs are to be ■cut off the entire right-of-way and removed back or under the spoil-banks, to the end that the right-of-way may have a clean, neat appearance.” The effect of this *1162provision was to require that all of the debris be placed either under the spoil-banks or removed from the right-of-way back of the spoil-banks; otherwisethe right-of-way could not “have a clean, neat appearance.” Under those terms of the contract, the debris could not be left exposed on the right-of-way, and if there was not sufficient deposit of waste dirt to constitute a spoil-bank to cover the debris, then, under the contract, it was appellee’s duty to remove it off of the right-of-way. The contract did not bind appellee to any particular method of doing the work, and he took his chances on doing it in any way that was necessary to accomplish the results specified in the contract. Notwithstanding the. fact that he expected to be able to do it with the dredge boat and it turned out that another and more expensive method of work was necessary, it was his loss and not that of the district.
There is much testimony concerning the correspondence and dealing’s between the parties with reference to this work, and it is contended that the conduct of the commissioners constituted an acquiescence in appellee’s doing the work on force account, but we are of the opinion that there was no waiver of the right of the district as to the method in which this work was to be done. It is true that the evidence shows that the commissioners knew that the clearing would have to be done with teams after thev passed station 429. but the recognition of this fact bv the commissioners did not commit them to an agreement to pay appellee extra for doing the work in that way.
The next item claimed by appellee and allowed bv the chancellor, in addition to the retained percentage,- is $10.623.72 on account of there being less than the guaranteed amount of excavation. In the specifications prepared by the engineer, which became part of the contract, there was set forth an itemized statement of the mileage of each ditch and the amount of cubic yards of dredging.-’ The aggregate mileage in this statement was 69.8 miles, and 3,046,850 cubic yards of dredging. The contract *1163contains the following provision with reference to guaranty of total yardage: ‘ ‘ The party of the first part (district) further agrees that it will guarantee to said party of the second part (contractor) an excavation of 90 per cent, of the total yardage in said district upon the total mileage as estimated by the engineer of said district.” According to the undisputed proof, appellant has been allowed for 3,227,127 cubic yards of dredging. This is 287,277 cubic yards in excess of the total yardage estimated for the whole project. But the. contention of appellee is that the language of the guaranty should be interpreted to mean that each item in the specification should be considered separately, so as to entitle him to an allowance of ninety per cent, of each item, regardless of the total. The contention is that the words, “as estimated by the engineer of said district,” confirm that interpretation. We do not so interpret the contract, for it appears to us that the language meant that the guaranty applied to the total yardage and not to a separate guaranty on each item. The court was therefore in error in allowing this item.
It is next contended that the court erred in allowing interest on the retained percentage from the date of the completion of the work on May 1, 1923, up to the date of the decree. We perceive no reason why appellee is not entitled to interest on the amount due him from the time it should have been paid to him on the completion of the contract. The funds were not to be retained any longer and the failure to pay at that time -started the period for which interest should be allowed. It is the contention of appellant that there should be no allowance of interest for the reason that appellee accepted payment on an estimate pursuant to the resolution of the board of commissioners to the effect thgt the payment should be'made “with the understanding that any floating timber that may enter the stream in the work now performed, shall be removed at the cost of the contractor.” There is no evidence that the *1164expense of removing- floating timber would amount to any considerable sum, but, even if it did, this would not prolong the period of payment beyond the completion of the contract in other respects. If there was any expense to the district on this account, there should be a deduction for the cost, but none is shown. There is a slight discrepancy of one month as to the date of the completion of the contract, it being claimed by one party that it was completed on June 1, and by the other that it was completed on May 1. ¥e accept the finding of the trial court as correct, that the contract was completed on May 1, and interest should run from that date.
This brings us to a consideration of the items of damage claimed by appellant in its cross-complaint.
There is a claim of damages in the sum of $24,160.23 for alleged defective work and for delay in completion of the work, and also the additional sum of $4,040 for extra engineering charges during the alleged overtime. We are of the opinion that the chancellor was correct in refusing to allow any part of these amounts. There appears to have been no complaint in regard to the work from station No. 3 up to station No. 340, but when the work reached station 429, estimate No. 34 was made by the engineer, dated June 6, 1921, with the following indorsement thereon: “I recommend that $537.23 be retained to cover the expense of removing logs from the right-of-way from station 340 to 429.” Pursuant to the recommendation, this amount was withheld by the board to cover the expense of doing that work, and the indorsement of the engineer must be taken as an estimate that this sum would be sufficient to remove the logs so as to complete the work. The clearing thereafter was satisfactorily done, and the only controversy arose over appellee’s claim for extra payment on force account. It is claimed that there were other defects for which damage should be allowed. There is a sharp conflict in the testimony as to the extent of those defects. The evidence is very voluminous. There is an enormous record *1165before ns, but, after having carefully considered it, we can do no more than state our conclusions from this testimony. We are of the opinion that appellant has not shown its right to recover any amount of damage in excess of the $537.23 retained for that purpose, and the retention of that item is not involved in the present controversy. The contract contained the following provision with respect to liquidated damages for delay in completion of the work.
“It is further agreed that if the party of the second part fails or refuses to complete said work in the manner and within the time specified herein, plus allowances made, then and in such event the party of the second part shall pay, in addition to the engineering and inspection charges made in the specifications, an amount equal to 6 per cent, a year on the total contract price to the commissioners of the said drainage district, as liquidated damages of said district for the entire time of such extension beyond the time allowed for completion as outlined in the specifications. ’ ’
Another provision on the subject of extension of time is as follows:
“No extension of time on account of lack of water, or for other causes, shall be made, unless the engineer shall be notified in writing of the necessity for delay, and shall decide that such necessity exists.”
And still another provision of the contract on that subject is as follows :
“But an unavoidable delay shall entitle him to an extension of time allowed for the completion of the work sufficient to cover the time lost by such delay.”
Another provision of the contract fixed thirty-eight months as the period within which the work should be completed.
The substance of these provisions, when read together, is that unavoidable delays or extensions of time with consent of the engineer are not chargeable against the contractor as delays for which damages are *1166to be allowed. There is proof that there were unavoidable delays, especially with reference to the change in the method of clearing the right-of-way below station 429. Communications between the parties show at least that the commissioners acquiesced in this method of doing the work, and there was no intimation of an intention to charge for the necessary delay in doing the work according' to the changed method. There is also proof of excessive rains and the overflow of a large part of the area to be drained, which necessarily delayed the work. We are of the opinion 'that the chancellor was correct in holding that no charge should be made on this account.
Adding to the amount of retained percentage, the item of $69.48 for error in computation, and the item of $3,985.73 .for interest from the date of the decree, makes a total of $75,818.38.
The decree dismissing the cross-complaint of appellant is therefore affirmed, and the decree in favor of appellee is modified so as to reduce the sum to be recovered to the amount last named above. It is so ordered.